BWXT 10-Q Quarterly Report March 31, 2014 | Alphaminr
BWX Technologies, Inc.

BWXT 10-Q Quarter ended March 31, 2014

BWX TECHNOLOGIES, INC.
10-Ks and 10-Qs
10-Q
10-Q
10-Q
10-K
10-Q
10-Q
10-Q
10-K
10-Q
10-Q
10-Q
10-K
10-Q
10-Q
10-Q
10-K
10-Q
10-Q
10-Q
10-K
10-Q
10-Q
10-Q
10-K
10-Q
10-Q
10-Q
10-K
10-Q
10-Q
10-Q
10-K
10-Q
10-Q
10-Q
10-K
10-Q
10-Q
10-Q
10-K
10-Q
10-Q
10-Q
10-K
10-Q
10-Q
10-Q
10-K
10-Q
10-Q
10-Q
10-K
10-Q
10-Q
10-Q
10-K
10-Q
10-Q
10-Q
10-K
10-Q
10-Q
PROXIES
DEF 14A
DEF 14A
DEF 14A
DEF 14A
DEF 14A
DEF 14A
DEF 14A
DEF 14A
DEF 14A
DEF 14A
DEF 14A
DEF 14A
DEF 14A
DEF 14A
DEF 14A
DEF 14A
DEF 14A
10-Q 1 d703892d10q.htm 10-Q 10-Q
Table of Contents

UNITED STATES

SECURITIES AND EXCHANGE COMMISSION

Washington, D. C. 20549

FORM 10-Q

(Mark One)

x QUARTERLY REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE SECURITIES EXCHANGE ACT OF 1934

For the quarterly period ended March 31, 2014

OR

¨ TRANSITION REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE SECURITIES EXCHANGE ACT OF 1934

For the transition period from to

Commission File No. 001-34658

THE BABCOCK & WILCOX COMPANY

(Exact name of registrant as specified in its charter)

DELAWARE 80-0558025
(State of Incorporation
or Organization)
(I.R.S. Employer
Identification No.)

THE HARRIS BUILDING

13024 BALLANTYNE CORPORATE PLACE

SUITE 700

CHARLOTTE, NORTH CAROLINA

28277
(Address of Principal Executive Offices) (Zip Code)

Registrant’s Telephone Number, Including Area Code: (704) 625-4900

Indicate by check mark whether the registrant (1) has filed all reports required to be filed by Section 13 or 15(d) of the Securities Exchange Act of 1934 during the preceding 12 months (or for such shorter period that the registrant was required to file such reports), and (2) has been subject to such filing requirements for the past 90 days.    Yes x No ¨

Indicate by check mark whether the registrant has submitted electronically and posted on its corporate Web site, if any, every Interactive Data File required to be submitted and posted pursuant to Rule 405 of Regulation S-T (§232.405 of this chapter) during the preceding 12 months (or for such shorter period that the registrant was required to submit and post such files).    Yes x No ¨

Indicate by check mark whether the registrant is a large accelerated filer, an accelerated filer, a non-accelerated filer, or a smaller reporting company. See the definitions of “large accelerated filer,” “accelerated filer” and “smaller reporting company” in Rule 12b-2 of the Exchange Act.

Large accelerated filer x Accelerated filer ¨
Non-accelerated filer ¨ (Do not check if a smaller reporting company) Smaller reporting company ¨

Indicate by check mark whether the registrant is a shell company (as defined in Rule 12b-2 of the Exchange Act).    Yes ¨ No x

The number of shares of the registrant’s common stock outstanding at April 30, 2014 was 110,286,153.


Table of Contents

THE BABCOCK & WILCOX COMPANY

I N D E X – F O R M 1 0 – Q

PAGE

PART I – FINANCIAL INFORMATION

Item 1 – Condensed Consolidated Financial Statements

2

Condensed Consolidated Balance Sheets March 31, 2014 and December 31, 2013 (Unaudited)

3

Condensed Consolidated Statements of Income Three Months Ended March 31, 2014 and 2013 (Unaudited)

5

Condensed Consolidated Statements of Comprehensive Income Three Months Ended March  31, 2014 and 2013 (Unaudited)

6

Condensed Consolidated Statements of Stockholders’ Equity Three Months Ended March  31, 2014 and 2013 (Unaudited)

7

Condensed Consolidated Statements of Cash Flows Three Months Ended March 31, 2014 and 2013 (Unaudited)

8

Notes to Condensed Consolidated Financial Statements

9

Item 2 – Management’s Discussion and Analysis of Financial Condition and Results of Operations

22

Item 3 – Quantitative and Qualitative Disclosures About Market Risk

32

Item 4 – Controls and Procedures

32

PART II – OTHER INFORMATION

Item 1 – Legal Proceedings

34

Item 1A – Risk Factors

34

Item 2 – Unregistered Sales of Equity Securities and Use of Proceeds

34

Item 4 – Mine Safety Disclosures

34

Item 6 – Exhibits

35

SIGNATURES

36

1


Table of Contents

PART I

THE BABCOCK & WILCOX COMPANY

FINANCIAL INFORMATION

Item 1. Condensed Consolidated Financial Statements

2


Table of Contents

THE BABCOCK & WILCOX COMPANY

CONDENSED CONSOLIDATED BALANCE SHEETS

ASSETS

March 31,
2014
December 31,
2013
(Unaudited)
(In thousands)

Current Assets:

Cash and cash equivalents

$ 208,055 $ 346,116

Restricted cash and cash equivalents

35,667 45,945

Investments

6,348 10,748

Accounts receivable – trade, net

328,197 360,323

Accounts receivable – other

66,906 45,480

Contracts in progress

425,202 370,820

Inventories

109,544 113,058

Deferred income taxes

97,401 97,170

Other current assets

61,724 47,764

Total Current Assets

1,339,044 1,437,424

Property, Plant and Equipment

1,138,908 1,126,683

Less accumulated depreciation

690,878 679,604

Net Property, Plant and Equipment

448,030 447,079

Investments

4,424 4,426

Goodwill

281,701 281,708

Deferred Income Taxes

119,018 127,076

Investments in Unconsolidated Affiliates

185,814 184,831

Intangible Assets

80,081 81,521

Other Assets

41,518 45,088

TOTAL

$ 2,499,630 $ 2,609,153

See accompanying notes to condensed consolidated financial statements.

3


Table of Contents

THE BABCOCK & WILCOX COMPANY

CONDENSED CONSOLIDATED BALANCE SHEETS

LIABILITIES AND STOCKHOLDERS’ EQUITY

March 31,
2014
December 31,
2013
(Unaudited)
(In thousands, except share
and per share amounts)

Current Liabilities:

Notes payable and current maturities of long-term debt

$ 5,083 $ 4,671

Accounts payable

233,765 319,774

Accrued employee benefits

157,072 163,833

Accrued liabilities – other

64,496 58,192

Advance billings on contracts

288,317 317,771

Accrued warranty expense

54,524 56,436

Income taxes payable

5,196 6,551

Total Current Liabilities

808,453 927,228

Long-Term Debt

15,000 225

Accumulated Postretirement Benefit Obligation

45,022 43,194

Environmental Liabilities

54,753 53,391

Pension Liability

320,093 336,878

Other Liabilities

59,169 65,296

Commitments and Contingencies (Note 4)

Stockholders’ Equity:

Common stock, par value $0.01 per share, authorized 325,000,000 shares; issued 121,090,224 and 120,536,910 shares at March 31, 2014 and December 31, 2013, respectively

1,211 1,205

Preferred stock, par value $0.01 per share, authorized 75,000,000 shares; No shares issued

Capital in excess of par value

754,274 747,189

Retained earnings

690,840 656,916

Treasury stock at cost, 10,682,307 and 10,068,731 shares at March 31, 2014 and December 31, 2013, respectively

(289,425 ) (268,971 )

Accumulated other comprehensive income

21,822 28,348

Stockholders’ Equity – The Babcock & Wilcox Company

1,178,722 1,164,687

Noncontrolling interest

18,418 18,254

Total Stockholders’ Equity

1,197,140 1,182,941

TOTAL

$ 2,499,630 $ 2,609,153

See accompanying notes to condensed consolidated financial statements.

4


Table of Contents

THE BABCOCK & WILCOX COMPANY

CONDENSED CONSOLIDATED STATEMENTS OF INCOME

Three Months Ended
March 31,
2014 2013
(Unaudited)
(In thousands, except share and per share amounts)

Revenues

$ 662,017 $ 805,423

Costs and Expenses:

Cost of operations

502,307 619,697

Research and development costs

23,996 28,346

Gains on asset disposals and impairments, net

(69 )

Selling, general and administrative expenses

94,685 103,600

Special charges for restructuring activities

2,658 8,423

Total Costs and Expenses

623,646 759,997

Equity in Income of Investees

15,269 14,787

Operating Income

53,640 60,213

Other Income (Expense):

Interest income

419 332

Interest expense

(899 ) (818 )

Other – net

1,322 1,406

Total Other Income

842 920

Income before Provision for Income Taxes

54,482 61,133

Provision for Income Taxes

13,328 16,257

Net Income

$ 41,154 $ 44,876

Net Loss Attributable to Noncontrolling Interest

3,890 2,298

Net Income Attributable to The Babcock & Wilcox Company

$ 45,044 $ 47,174

Earnings per Common Share:

Basic:

Net Income Attributable to The Babcock & Wilcox Company

$ 0.41 $ 0.41

Diluted:

Net Income Attributable to The Babcock & Wilcox Company

$ 0.41 $ 0.41

Shares used in the computation of earnings per share (Note 9):

Basic

110,439,415 114,097,313

Diluted

110,886,043 114,737,154

See accompanying notes to condensed consolidated financial statements.

5


Table of Contents

THE BABCOCK & WILCOX COMPANY

CONDENSED CONSOLIDATED STATEMENTS OF COMPREHENSIVE INCOME

Three Months Ended
March 31,
2014 2013

(Unaudited)

(In thousands)

Net Income

$ 41,154 $ 44,876

Other Comprehensive Income (Loss):

Currency translation adjustments

(6,611 ) (3,744 )

Derivative financial instruments:

Unrealized losses arising during the period, net of tax benefit of $339 and $837, respectively

(975 ) (2,161 )

Reclassification adjustment for losses included in net income, net of tax benefit of $(221) and $(358), respectively

632 1,047

Amortization of benefit plan costs, net of tax benefit of $(197) and $(273), respectively

397 528

Investments:

Unrealized gains arising during the period, net of tax provision of $(25) and $(44), respectively

46 95

Reclassification adjustment for gains included in net income, net of tax provision of $12 and $0, respectively

(22 ) (714 )

Other Comprehensive Loss

(6,533 ) (4,949 )

Total Comprehensive Income

34,621 39,927

Comprehensive Loss Attributable to Noncontrolling Interest

3,897 2,299

Comprehensive Income Attributable to The Babcock & Wilcox Company

$ 38,518 $ 42,226

See accompanying notes to condensed consolidated financial statements.

6


Table of Contents

THE BABCOCK & WILCOX COMPANY

CONDENSED CONSOLIDATED STATEMENTS OF STOCKHOLDERS’ EQUITY

Accumulated
Other
Comprehensive
Income (Loss)
Capital In
Excess of
Par Value
Total
Stockholders’
Equity
Common Stock Retained
Earnings
Treasury
Stock
Stockholders’
Equity
Noncontrolling
Interest
Shares Par Value
(In thousands, except share and per share amounts)

Balance December 31, 2013

120,536,910 $ 1,205 $ 747,189 $ 656,916 $ 28,348 $ (268,971 ) $ 1,164,687 $ 18,254 $ 1,182,941

Net income

45,044 45,044 (3,890 ) 41,154

Dividends declared ($.10 per share)

(11,120 ) (11,120 ) (11,120 )

Defined benefit obligations

397 397 397

Available-for-sale investments

24 24 24

Currency translation adjustments

(6,604 ) (6,604 ) (7 ) (6,611 )

Derivative financial instruments

(343 ) (343 ) (343 )

Exercise of stock options

76,308 1 2,455 2,456 2,456

Contributions to thrift plan

86,727 1 2,930 2,931 2,931

Shares placed in treasury

(20,454 ) (20,454 ) (20,454 )

Stock-based compensation charges

390,279 4 1,700 1,704 1,704

Contribution of in-kind services

4,173 4,173

Distributions to noncontrolling interests

(112 ) (112 )

Balance March 31, 2014 (unaudited)

121,090,224 $ 1,211 $ 754,274 $ 690,840 $ 21,822 $ (289,425 ) $ 1,178,722 $ 18,418 $ 1,197,140

Balance December 31, 2012

119,608,026 $ 1,196 $ 713,257 $ 349,063 $ 32,728 $ (109,809 ) $ 986,435 $ 16,481 $ 1,002,916

Net income

47,174 47,174 (2,298 ) 44,876

Dividends declared ($.08 per share)

(9,150 ) (9,150 ) (9,150 )

Defined benefit obligations

528 528 528

Available-for-sale investments

(619 ) (619 ) (619 )

Currency translation adjustments

(3,743 ) (3,743 ) (1 ) (3,744 )

Derivative financial instruments

(1,114 ) (1,114 ) (1,114 )

Exercise of stock options

39,385 1 808 809 809

Contributions to thrift plan

109,405 1 2,952 2,953 2,953

Shares placed in treasury

(59,000 ) (59,000 ) (59,000 )

Stock-based compensation charges

194,329 2 4,272 4,274 4,274

Contribution of in-kind services

3,020 3,020

Distributions to noncontrolling interests

(102 ) (102 )

Balance March 31, 2013 (unaudited)

119,951,145 $ 1,200 $ 721,289 $ 387,087 $ 27,780 $ (168,809 ) $ 968,547 $ 17,100 $ 985,647

See accompanying notes to condensed consolidated financial statements.

7


Table of Contents

THE BABCOCK & WILCOX COMPANY

CONDENSED CONSOLIDATED STATEMENTS OF CASH FLOWS

Three Months Ended
March 31,
2014 2013

(Unaudited)

(In thousands)

CASH FLOWS FROM OPERATING ACTIVITIES:

Net Income

$ 41,154 $ 44,876

Non-cash items included in net income:

Depreciation and amortization

17,013 17,358

Income of investees, net of dividends

(4,694 ) (7,585 )

Gains on asset disposals

(69 )

In-kind research and development costs

4,173 3,020

Recognition of losses for pension and postretirement plans

594 801

Stock-based compensation expense

1,704 4,274

Excess tax benefits from stock-based compensation

(760 ) (13 )

Changes in assets and liabilities:

Accounts receivable

17,528 (13,757 )

Accounts payable

(82,164 ) 20,305

Contracts in progress and advance billings on contracts

(83,797 ) (70,775 )

Inventories

3,082 5,864

Income taxes

(6,766 ) 3,827

Accrued and other current liabilities

(31 ) 17,508

Pension liability, accrued postretirement benefit obligation and employee benefits

(20,913 ) (38,666 )

Other, net

360 (13,283 )

NET CASH USED IN OPERATING ACTIVITIES

(113,517 ) (26,315 )

CASH FLOWS FROM INVESTING ACTIVITIES:

Decrease in restricted cash and cash equivalents

10,278 360

Purchases of property, plant and equipment

(21,214 ) (18,799 )

Purchase of intangible assets

(2,200 )

Purchases of available-for-sale securities

(19,926 ) (47,933 )

Sales and maturities of available-for-sale securities

24,390 43,268

Proceeds from asset disposals

3 726

Investment in equity and cost method investees

(4,900 ) (2,730 )

NET CASH USED IN INVESTING ACTIVITIES

(11,369 ) (27,308 )

CASH FLOWS FROM FINANCING ACTIVITIES:

Payment of short-term borrowing and long-term debt

(441 ) (52 )

Increase in short-term borrowing

733

Borrowings under the Credit Agreement

15,000

Repurchase of common shares

(15,665 ) (57,074 )

Dividends paid to common shareholders

(11,099 ) (9,145 )

Exercise of stock options

2,191 813

Excess tax benefits from stock-based compensation

760 13

Other

(112 ) (102 )

NET CASH USED IN FINANCING ACTIVITIES

(8,633 ) (65,547 )

EFFECTS OF EXCHANGE RATE CHANGES ON CASH

(4,542 ) (3,261 )

NET DECREASE IN CASH AND CASH EQUIVALENTS

(138,061 ) (122,431 )

CASH AND CASH EQUIVALENTS AT BEGINNING OF PERIOD

346,116 383,547

CASH AND CASH EQUIVALENTS AT END OF PERIOD

$ 208,055 $ 261,116

SUPPLEMENTAL DISCLOSURES OF CASH FLOW INFORMATION:

Cash paid during the period for:

Income taxes (net of refunds)

$ 15,088 $ 11,239

SCHEDULE OF NON-CASH INVESTING ACTIVITY:

Accrued capital expenditures included in accounts payable

$ 4,854 $ 4,035

See accompanying notes to condensed consolidated financial statements.

8


Table of Contents

THE BABCOCK & WILCOX COMPANY

NOTES TO CONDENSED CONSOLIDATED FINANCIAL STATEMENTS

MARCH 31, 2014

(UNAUDITED)

NOTE 1 – BASIS OF PRESENTATION AND SIGNIFICANT ACCOUNTING POLICIES

We have presented our condensed consolidated financial statements in U.S. Dollars in accordance with the interim reporting requirements of Form 10-Q and Rule 10-01 of Regulation S-X. Certain financial information and disclosures normally included in our financial statements prepared annually in accordance with accounting principles generally accepted in the United States (“GAAP”) have been condensed or omitted. Readers of these financial statements should, therefore, refer to the consolidated financial statements and notes in our annual report on Form 10-K for the year ended December 31, 2013 (our “2013 10-K”). We have included all adjustments, in the opinion of management, consisting only of normal recurring adjustments, necessary for a fair presentation.

We use the equity method to account for investments in entities that we do not control, but over which we have the ability to exercise significant influence. We generally refer to these entities as “joint ventures.” We have eliminated all intercompany transactions and accounts. We present the notes to our condensed consolidated financial statements on the basis of continuing operations, unless otherwise stated.

Unless the context otherwise indicates, “we,” “us” and “our” mean The Babcock & Wilcox Company (“B&W”) and its consolidated subsidiaries.

Reporting Segments

We operate in five reportable segments: Power Generation, Nuclear Operations, Technical Services, Nuclear Energy and mPower. Our reportable segments are further described as follows:

Our Power Generation segment provides an advanced, clean and diverse portfolio of steam generating equipment, proven emissions control systems for environmental regulations, renewable energy solutions (biomass, combined heat and power, waste-to-energy and concentrating solar power), boiler cleaning systems, material transport equipment, fuel handling systems, cogeneration and combined cycle installations, and carbon-capture and sequestration technologies. For this full range of product offerings, we offer complete aftermarket, operation and maintenance and construction project services. We provide products and services to electric utilities, municipalities, EPC contractors, architect engineers, independent power producers, international trading firms, electric power cooperatives and state electricity boards. Our markets include electric power generation, industrial, pulp and paper, chemical, oil refinery, cement, institutional, municipal and government customers worldwide. We have an extensive North American and global footprint including engineering, design, service, manufacturing, sales, business development, regional service centers, manufacturers representatives and joint venture facilities located in more than 30 countries around the globe. We have supplied product and services for more than 300,000 MW of installed electric generating capacity in more than 80 countries.

Our steam generating equipment operates on a range of traditional fossil fuels including coal, natural gas and oil along with renewable, unconventional and other typical waste fuel streams. We have commercialized many advanced emissions technologies to control nitrogen oxide, sulfur dioxide, sulfur trioxide, coarse and fine particulate matter, mercury, acid gases and other hazardous air emissions.

Our Nuclear Operations segment manufactures naval nuclear reactors for the U.S. Department of Energy (“DOE”)/National Nuclear Security Administration’s (“NNSA”) Naval Nuclear Propulsion Program, which in turn supplies them to the U.S. Navy for use in submarines and aircraft carriers. Through this segment, we own and operate manufacturing facilities located in Lynchburg, Virginia; Mount Vernon, Indiana; Euclid, Ohio; Barberton, Ohio; and Erwin, Tennessee. The Barberton and Mount Vernon locations specialize in the design and manufacture of heavy components. These two locations are N-Stamp certified by the American Society of Mechanical Engineers (“ASME”), making them two of only a few North American suppliers of large, heavy-walled nuclear components and vessels. The Euclid facility, which is also ASME N-Stamp certified, fabricates electro-mechanical equipment for the U.S. Government, and performs design, manufacturing, inspection, assembly and testing activities. The Lynchburg operations fabricate fuel-bearing precision components that range in weight from a few grams to hundreds of tons. In-house capabilities also

9


Table of Contents

include wet chemistry uranium processing, advanced heat treatment to optimize component material properties and a controlled, clean-room environment with the capacity to assemble railcar-size components. Fuel for the naval nuclear reactors is provided by Nuclear Fuel Services, Inc. (“NFS”), one of our wholly owned subsidiaries. Located in Erwin, NFS also converts Cold War-era government stockpiles of highly enriched uranium into material suitable for further processing into commercial nuclear reactor fuel.

Our Technical Services segment provides various services to the U.S. Government, including uranium processing, environmental site restoration services and management and operating services for various U.S. Government-owned facilities. These services are provided to the Department of Defense and the DOE, including the NNSA, the Office of Nuclear Energy, the Office of Science and the Office of Environmental Management. Through this segment we deliver products and management solutions to nuclear operations and high-consequence manufacturing facilities. A significant portion of this segment’s operations are conducted through joint ventures.

Our Nuclear Energy segment supplies commercial nuclear steam generators and components to nuclear utility customers. B&W has supplied the nuclear industry with more than 1,300 large, heavy components worldwide. This segment is the only heavy nuclear component, N-Stamp certified manufacturer in North America. Our Nuclear Energy segment fabricates pressure vessels, reactors, steam generators, heat exchangers and other auxiliary equipment. This segment also provides specialized engineering services that include structural component design, 3-D thermal-hydraulic engineering analysis, weld and robotic process development and metallurgy and materials engineering. Our Nuclear Energy segment also provides power plant construction and management and maintenance services. In addition, this segment offers services for nuclear steam generators and balance of plant equipment, as well as nondestructive examination and tooling/repair solutions for other plant systems and components.

Our mPower segment is designing the B&W mPower TM reactor, a small modular reactor (“SMR”) design generally based on proven light-water nuclear technology and able to operate for four years without refueling. Through our majority-owned joint venture, Generation mPower LLC (“GmP”), we are developing the associated mPower Plant power generating facility, which will use two B&W mPower TM reactors to generate 360 MW within an advanced passively safe and secure plant architecture. As part of this initiative, we were selected to receive funding pursuant to a Cooperative Agreement with the DOE under its Small Modular Reactor Licensing Technical Support Program (the “Funding Program”) for SMR deployment by 2022. This Funding Program provides financial assistance for our mPower Plant design, engineering and licensing activities supporting the planned first mPower Plant commercial operation date by 2022. On April 14, 2014, we announced our plans to restructure the mPower program to focus on technology development. Beginning in the third quarter of 2014, we expect to slow the pace of development and invest no more than $15 million on an annual basis. We intend to work with the DOE to amend the Funding Program, including mutually agreeable program milestones for continued funding. If a mutually agreeable plan is not identified, future amounts may not be made available to us under the Funding Program.

See Note 8 for further information regarding our segments.

Operating results for the three months ended March 31, 2014 are not necessarily indicative of the results that may be expected for the year ending December 31, 2014. For further information, refer to the consolidated financial statements and the related footnotes included in our 2013 10-K.

Contracts and Revenue Recognition

We generally recognize contract revenues and related costs on a percentage-of-completion method for individual contracts or combinations of contracts based on work performed, man hours, or a cost-to-cost method, as applicable to the product or activity involved. We recognize estimated contract revenue and resulting income based on the measurement of the extent of progress completion as a percentage of the total project. Certain costs may be excluded from the cost-to-cost method of measuring progress, such as significant costs for materials and major third party subcontractors, if it appears that such exclusion would result in a more meaningful measurement of actual contract progress and resulting periodic allocation of income. We include revenues and related costs so recorded, plus accumulated contract costs that exceed amounts invoiced to customers under the terms of the contracts, in contracts in progress. We include in advance billings on contracts billings that exceed accumulated contract costs and revenues and costs recognized under the percentage-of-completion method. Most long-term contracts contain provisions for progress

10


Table of Contents

payments. Our unbilled receivables do not contain an allowance for credit losses as we expect to invoice customers and collect all amounts for unbilled revenues. We review contract price and cost estimates periodically as the work progresses and reflect adjustments proportionate to the percentage-of-completion in income in the period when those estimates are revised. For all contracts, if a current estimate of total contract cost indicates a loss on a contract, the projected loss is recognized in full when determined.

For contracts as to which we are unable to estimate the final profitability except to assure that no loss will ultimately be incurred, we recognize equal amounts of revenue and cost until the final results can be estimated more precisely. For these deferred profit recognition contracts, we recognize revenue and cost equally and only recognize gross margin when probable and reasonably estimable, which we generally determine to be when the contract is approximately 70% complete. We treat long-term construction contracts that contain such a level of risk and uncertainty that estimation of the final outcome is impractical, except to assure that no loss will be incurred, as deferred profit recognition contracts.

Our policy is to account for fixed-price contracts under the completed-contract method if we believe that we are unable to reasonably forecast cost to complete at start-up. Under the completed-contract method, income is recognized only when a contract is completed or substantially complete.

For parts orders and certain aftermarket services activities, we recognize revenues as goods are delivered and work is performed.

Variations from estimated contract performance could result in material adjustments to operating results for any fiscal quarter or year. We include claims for extra work or changes in scope of work to the extent of costs incurred in contract revenues when we believe collection is probable.

In the three months ended March 31, 2014, we recorded contract losses totaling $7.6 million for additional estimated costs to complete our Berlin Station project which includes estimated potential letter of credit draws for liquidated damages. These losses are in addition to contract losses recorded for this project during 2013 and 2012. We have asserted that substantial completion has been achieved on this project. We believe these contract losses as well as costs associated with any further delays to complete this project, beyond the delays already caused by the customer during construction or otherwise excusable under the contract, are the result of the customer’s failure to supply fuel complying with the contract specifications. See Note 4 for legal proceedings associated with this matter.

Comprehensive Income

The components of accumulated other comprehensive income included in stockholders’ equity are as follows:

March 31,
2014
December 31,
2013
(In thousands)

Currency translation adjustments

$ 31,811 $ 38,415

Net unrealized gain on investments

154 130

Net unrealized gain on derivative financial instruments

284 627

Unrecognized prior service cost on benefit obligations

(10,427 ) (10,824 )

Accumulated other comprehensive income

$ 21,822 $ 28,348

11


Table of Contents

The amounts reclassified out of accumulated other comprehensive income by component and the affected condensed consolidated statements of income line items are as follows:

Three Months Ended

March 31,

2014 2013

Accumulated Other Comprehensive Income

Component Recognized

(In thousands)

Line Item Presented

Realized (losses) gains on derivative financial instruments

$ 163 $ (531 ) Revenues
(1,026 ) (889 ) Cost of operations
10 15 Other-net

(853 ) (1,405 ) Total before tax
221 358 Provision for Income Taxes

$ (632 ) $ (1,047 ) Net Income

Amortization of prior service cost on benefit obligations

$ (509 ) $ (751 ) Cost of operations
(85 ) (50 ) Selling, general and administrative expenses

(594 ) (801 ) Total before tax
197 273 Provision for Income Taxes

$ (397 ) $ (528 ) Net Income

Realized gain on investments

$ 34 $ 714 Other-net
(12 ) Provision for Income Taxes

$ 22 $ 714 Net Income

Total reclassification for the period

$ (1,007 ) $ (861 )

Inventories

The components of inventories are as follows:

March 31,
2014
December 31,
2013
(In thousands)

Raw materials and supplies

$ 80,473 $ 85,455

Work in progress

9,874 10,872

Finished goods

19,197 16,731

Total inventories

$ 109,544 $ 113,058

Restricted Cash and Cash Equivalents

At March 31, 2014, we had restricted cash and cash equivalents totaling $38.5 million, $3.7 million of which was held in restricted foreign cash accounts, $2.8 million of which was held for future decommissioning of facilities (which is included in other assets on our condensed consolidated balance sheets), and $32.0 million of which was held to meet reinsurance reserve requirements of our captive insurer (in lieu of long-term investments).

Warranty Expense

We accrue estimated expense included in cost of operations on our condensed consolidated statements of income to satisfy contractual warranty requirements when we recognize the associated revenue on the related contracts. In addition, we record specific provisions or reductions where we expect the actual warranty costs to significantly differ from the accrued estimates. Such changes could have a material effect on our consolidated financial condition, results of operations and cash flows.

12


Table of Contents

The following summarizes the changes in the carrying amount of our accrued warranty expense:

Three Months Ended

March 31,

2014 2013
(In thousands)

Balance at beginning of period

$ 56,436 $ 83,682

Additions

3,590 4,903

Expirations and other changes

(3,718 ) 131

Payments

(1,559 ) (5,279 )

Translation and other

(225 ) (572 )

Balance at end of period

$ 54,524 $ 82,865

Research and Development

Our research and development activities are related to the development and improvement of new and existing products and equipment, as well as conceptual and engineering evaluation for translation into practical applications. We charge research and development costs unrelated to specific contracts as they are incurred. Substantially all of these costs are in our Power Generation and mPower segments, the majority of which are related to the development of our B&W mPower TM reactor and the associated mPower Plant.

During the three months ended March 31, 2014 and 2013, we recognized $4.2 million and $3.0 million, respectively, of non-cash in-kind research and development costs related to services contributed by our minority partner to GmP, our majority-owned subsidiary formed in 2011 to oversee the program to develop the small modular nuclear power plant based on B&W mPower TM technology.

On April 12, 2013, Babcock & Wilcox mPower, Inc., a wholly-owned subsidiary of B&W, entered into a Cooperative Agreement establishing the terms and conditions of a funding award totaling $150 million under the DOE’s Funding Program. This cost-sharing award requires us to use the DOE funds to cover first-of-a-kind engineering costs associated with SMR design certification and licensing efforts. The DOE will provide cost reimbursement for up to 50% of qualified expenditures incurred from April 1, 2013 to March 31, 2018. The DOE has authorized $99.3 million of funding to B&W for this award program as of March 31, 2014. Congress has allocated and designated an additional $85 million from the 2014 budget to the Cooperative Agreement; however, the DOE has not yet obligated those funds to us. In the three months ended March 31, 2014, we recognized $17.1 million associated with the funding award. We have recognized all amounts currently authorized by the DOE under the Cooperative Agreement. At March 31, 2014, we had $19.2 million of receivables outstanding from the DOE related to the funding award.

On April 14, 2014, we announced our plans to restructure the mPower program to focus on technology development. Beginning in the third quarter of 2014, we expect to slow the pace of development and invest no more than $15 million on an annual basis. We intend to work with the DOE to amend the Funding Program, including mutually agreeable program milestones for continued funding. If a mutually agreeable plan is not identified, future amounts may not be made available to us under the Funding Program.

Provision for Income Taxes

We are subject to U.S. federal income tax and income tax of multiple state and international jurisdictions. We provide for income taxes based on the enacted tax laws and rates in the jurisdictions in which we conduct our operations. These jurisdictions may have regimes of taxation that vary with respect to nominal rates and with respect to the basis on which these rates are applied. This variation, along with changes in our mix of income within these jurisdictions, can contribute to shifts in our effective tax rate from period to period. We classify interest and penalties related to taxes (net of any applicable tax benefit) as a component of provision for income taxes on our condensed consolidated statements of income.

Our effective tax rate for the three months ended March 31, 2014 was approximately 24.5% as compared to 26.6% for the three months ended March 31, 2013. The effective tax rate for the three months ended March 31, 2014 was lower than our statutory rate primarily due to the receipt of a favorable ruling from the Internal Revenue Service that will allow us to amend prior year U.S. income tax returns to exclude distributions of several of our foreign joint ventures from domestic taxable income. Our effective tax rate for the three months ended March 31, 2013 reflected the impact of certain tax benefits related to the retroactive provisions of the American Taxpayer Relief Act of 2012, which was enacted on January 2, 2013.

13


Table of Contents

As of March 31, 2014, we have gross unrecognized tax benefits of $6.0 million which, if recognized, would impact our effective tax rate from continuing operations.

New Accounting Pronouncements

In April 2014, the Financial Accounting Standards Board issued an update to the Topics Presentation of Financial Statements and Property, Plant and Equipment . This update changes the criteria for reporting discontinued operations such that a disposal of a component of an entity will be required to be reported in discontinued operations if the disposal represents a strategic shift that has (or will have) a major effect on an entity’s operations and financial results. This update is effective in 2015, but early adoption is permitted. We are currently evaluating the effect of this update on our financial statements.

Other than as described above, there have been no material changes to the recent pronouncements discussed in our 2013 10-K.

NOTE 2 – SPECIAL CHARGES FOR RESTRUCTURING ACTIVITIES

Global Competitiveness Initiative

In the third quarter of 2012, we announced the Global Competitiveness Initiative (“GCI”) to enhance competitiveness, better position B&W for growth and improve profitability. In conjunction with GCI, during the three months ended March 31, 2014, we incurred $0.2 million of expenses related to employee termination benefits and $1.3 million of expenses related to facility consolidation. During the three months ended March 31, 2013, we recorded $4.3 million of expenses related to employee termination benefits and $4.1 million of expenses related to consulting and administrative costs.

Other Restructuring Actions

We incurred additional expenses related to employee termination benefits totaling $0.4 million for the three months ended March 31, 2014 related to the restructuring of our governmental segments. In addition, we incurred consulting and administrative costs totaling $0.8 million for the three months ended March 31, 2014 related to the restructuring of our mPower program.

The following summarizes the changes in our restructuring liability for the three months ended March 31, 2014 and 2013:

Three Months Ended

March 31,

2014 2013
(In thousands)

Balance at beginning of period

$ 10,054 $

Special charges for restructuring activities (1)

1,724 8,423

Payments

(5,418 ) (4,152 )

Translation and other

(160 )

Balance at end of period

$ 6,200 $ 4,271

(1) The charges in the three months ended March 31, 2014 exclude accelerated depreciation of $0.9 million, which did not impact the restructuring liability.

At March 31, 2014, unpaid restructuring charges total $5.3 million for employee termination benefits, $0.8 million for consulting and administrative costs and $0.1 million for facility consolidation.

14


Table of Contents

NOTE 3 – PENSION PLANS AND POSTRETIREMENT BENEFITS

Components of net periodic benefit cost included in net income are as follows:

Pension Benefits
Three Months Ended
March 31,
Other Benefits
Three Months Ended
March 31,
2014 2013 2014 2013
(In thousands)

Service cost

$ 9,646 $ 11,578 $ 216 $ 248

Interest cost

30,327 27,788 969 905

Expected return on plan assets

(37,377 ) (36,670 ) (575 ) (538 )

Amortization of prior service cost (credit)

634 792 (40 ) 9

Net periodic benefit cost

$ 3,230 $ 3,488 $ 570 $ 624

We made contributions to our pension and postretirement benefit plans totaling $8.6 million and $25.2 million during the three months ended March 31, 2014 and 2013, respectively.

NOTE 4 – COMMITMENTS AND CONTINGENCIES

Other than as noted below, there have been no material changes during the period covered by this Form 10-Q in the status of the legal proceedings disclosed in Note 11 to the consolidated financial statements in Part II of our 2013 10-K.

Investigations and Litigation

Apollo and Parks Township

In January 2010, Michelle McMunn, Cara D. Steele and Yvonne Sue Robinson filed suit against Babcock & Wilcox Power Generation Group, Inc. (“B&W PGG”), Babcock & Wilcox Technical Services Group, Inc., formerly known as B&W Nuclear Environmental Services, Inc. (the “B&W Parties”) and Atlantic Richfield Company (“ARCO”) in the United States District Court for the Western District of Pennsylvania. Since January 2010, additional suits have been filed by additional plaintiffs and there are currently fourteen lawsuits pending in the U.S. District Court for the Western District of Pennsylvania against the B&W Parties and ARCO. Following the dismissal of a number of claims in June 2012, 10 additional primary claims were filed on February 4, 2013, followed by the filing of 2 additional primary claims on May 17, 2013 and 8 additional primary claims on October 21, 2013. In total, the suits presently involve approximately 95 primary claimants. Plaintiffs have filed motions to dismiss, with prejudice, 3 claims and have agreed to dismiss, with prejudice, 3 additional claims, which would reduce the total number of primary claimants to 89. The primary claimants allege, among other things, personal injuries and property damage as a result of alleged releases of radioactive material relating to the operation, remediation, and/or decommissioning of two former nuclear fuel processing facilities located in Apollo Borough and Parks Township, Pennsylvania (collectively, the “Apollo and Parks Litigation”). Those facilities previously were owned by Nuclear Materials and Equipment Company, a former subsidiary of ARCO (“NUMEC”), which was acquired by B&W PGG. The plaintiffs in the Apollo and Parks Litigation seek compensatory and punitive damages. All of the suits, except for the most recent filing, have been consolidated for non-dispositive pre-trial matters. Fact discovery in the Apollo and Parks Litigation is now closed, but no trial date has been set.

At the time of ARCO’s sale of NUMEC stock to B&W PGG, B&W PGG received an indemnity and hold harmless agreement from ARCO with respect to claims and liabilities arising prior to or as a result of conduct or events predating the acquisition.

Insurance coverage and/or the ARCO indemnity currently provides coverage for the claims alleged in the Apollo and Parks Litigation, although no assurance can be given that insurance and/or the indemnity will be available or sufficient in the event of liability, if any.

The B&W Parties and ARCO were defendants in a prior litigation filed in 1994 relating to the operation of the Apollo and Parks Township facilities in the matter of Donald F. Hall and Mary Ann Hall, et al., v. Babcock & Wilcox Company, et al. (the “Hall Litigation”). In 1998, the B&W Parties settled all then-pending and future punitive damage claims in the Hall Litigation for $8.0 million and sought reimbursement from third parties,

15


Table of Contents

including its insurers, American Nuclear Insurers and Mutual Atomic Energy Liability Underwriters (“ANI”). In 2008, ARCO settled the Hall Litigation with the plaintiffs for $27.5 million. The B&W Parties then settled the Hall Litigation in 2009 for $52.5 million, settling approximately 250 personal injury and wrongful death claims, as well as approximately 125 property damage claims, alleging damages as a result of alleged releases involving the facilities. ARCO and the B&W Parties retained their insurance rights against ANI in their respective settlements; however, under a related settlement regarding ARCO’s indemnification of B&W PGG relating to the two facilities, ARCO assigned to the B&W Parties 58.33% of the total of all ARCO’s proceeds/amounts recovered against ANI on account of the Hall Litigation.

The B&W Parties sought recovery from ANI for amounts paid by the B&W Parties to settle the Hall Litigation, along with unreimbursed attorneys fees, allocated amounts assigned by ARCO to the B&W Parties, and applicable interest based upon ANI’s breach of contract and bad faith conduct in the matter of The Babcock & Wilcox Company et al. v. American Nuclear Insurers, et al. (the “ANI Litigation”). ARCO also sought recovery against ANI in the ANI Litigation, which has been pending before the Court of Common Pleas of Allegheny County, Pennsylvania.

In September 2011, a jury returned a verdict in the ANI Litigation, finding that the B&W Parties’ settlement of the Hall Litigation for $52.5 million and ARCO’s settlement for $27.5 million were fair and reasonable. Following the verdict, in February 2012, the B&W Parties, ARCO and ANI entered into an agreement in which the parties agreed to the dismissal with prejudice of all remaining claims pending in the ANI Litigation, excluding the B&W Parties’ and ARCO’s claims seeking reimbursement from ANI for the $52.5 million and $27.5 million settlements (plus interest) (the “Settlement Claims”). By agreement, ANI also waived: (1) any and all rights to appeal the September 2011 jury verdict on the basis of the trial court’s evidentiary rulings; and (2) any defenses and arguments of any kind except ANI’s position that it was not required to reimburse the B&W Parties’ and ARCO for their settlements under the provisions of the ANI policies. In February 2012, the Court granted the parties’ proposed order implementing their agreement and entered final judgment in favor of the B&W Parties and ARCO on the Settlement Claims. As part of the final order and judgment, the Court ruled that the B&W Parties and ARCO are entitled to pre-judgment interest on their $52.5 million and $27.5 million settlements, in the amounts of approximately $8.8 million and $6.2 million, respectively. In addition, post-verdict interest from the date of the jury verdict was awarded at 6%. In March 2012, ANI filed a notice of appeal as to the final judgment and a supersedeas appeal bond in the amount of 120% of the total final judgment amount. The parties filed their respective briefs with the Superior Court and oral arguments were held October 31, 2012.

In July 2013, the Superior Court reversed the judgment of the trial court with instructions to reconsider the issue of the Settlement Claims under a different standard. In August 2013, B&W and ARCO filed a request for appeal of the Superior Court’s decision to the Pennsylvania Supreme Court. On January 24, 2014, the Supreme Court of Pennsylvania granted B&W and ARCO’s request for appeal. The parties’ briefs on the appeal have been filed, but the date for oral arguments has not been set. B&W has not recognized any amounts claimed in the ANI Litigation in its financial statements due to the uncertainty surrounding the ultimate amount to be realized.

Berlin Station

Our subsidiary, Babcock & Wilcox Construction Co., Inc. (“BWCC”), is currently in a dispute with a customer in connection with a 75MW biomass-energy power plant that BWCC designed and built in Berlin, New Hampshire. The dispute primarily concerns (1) material claims by BWCC against its customer for contract changes relating to schedule delays, delay costs and extra work and (2) whether liquidated damages for delay (“Delay LDs”) are due to the customer under the contract. The customer contends it is owed Delay LDs, capped under the terms of the contract at approximately $18.7 million, and has made three partial draws totaling approximately $4.9 million against $44 million of letters of credit from BWCC. These draws correspond to a total of approximately $5.8 million in alleged Delay LDs (approximately $3.3 million related to the period commencing October 16, 2013 through December 31, 2013, $1.3 million for the period from January 1, 2014 through January 31, 2014 and $1.2 million for the period from February 1, 2014 through February 28, 2014). BWCC has asserted that substantial completion has been achieved and that any further delays to completion of the project, beyond the delays already caused by the customer during construction or otherwise excusable under the contract are the result of the customer’s failure to supply fuel complying with the contract specifications. On April 9, 2014, BWCC was granted a temporary restraining order (“TRO”) that restrains the customer from making further draws against BWCC’s letters of credit in connection with its claims for liquidated damages associated with substantial completion of the project. BWCC has also filed a motion for an injunction to prevent further draws on BWCC’s letters of credit for such claims. The court has not ruled on this motion as of the filing date of this report, but the TRO will remain in effect until a decision is rendered.

16


Table of Contents

BWCC’s aggregate liquidated damages cap under the contract is approximately $37.4 million, which also includes an $18.7 million cap for performance LDs. Notwithstanding the TRO, there is a risk that the customer will attempt to call all or part of the letters of credit during the pendency of this matter. We believe any such call would be wrongful and entitle us to return of the funds and other damages. Nevertheless, we have made provisions in our financial statements totaling $11.0 million based on Delay LDs called to date and management’s estimation of further calls against the letters of credit and have not recorded offsetting claims revenue in our financial statements.

Following the customer’s denial of BWCC’s change order request relating to schedule delays, delay costs and extra work, on January 16, 2014, BWCC filed suit against the customer in the Court of Common Pleas, Summit County, Ohio, Case No. 2014 01 0208, seeking damages in excess of $37 million. BWCC’s suit asserts counts including the customer’s breach of contract, fraud, constructive fraud, negligent misrepresentation, fraudulent inducement and fraudulent concealment. In addition, BWCC has submitted claims to the customer based on the customer’s failure to supply fuel complying with the contract specifications that has resulted (and continues to result) in further delays, reduced plant performance abilities and damage to plant equipment. In the aggregate, we intend to seek recovery for damages incurred to date in excess of $50 million. On or about January 30, 2014, BWCC’s customer filed suit against BWCC in the Superior Court of Coos County, New Hampshire, Case No. 214-2014-CV-14 alleging breach of contract and seeking unspecified amounts.

We believe BWCC has sound legal and factual bases for its claims. BWCC intends to aggressively pursue recovery on its claims, including recovery of the wrongful calls against BWCC’s letters of credit. However, it is premature to predict the outcome of this matter. The litigation could be lengthy, and if BWCC’s customer were to prevail completely or substantially in this matter, the outcome could have a material adverse effect on our financial statements.

NOTE 5 – DERIVATIVE FINANCIAL INSTRUMENTS

Our global operations give rise to exposure to market risks from changes in foreign currency exchange (“FX”) rates. We use derivative financial instruments, primarily FX forward contracts, to reduce the impact of changes in FX rates on our operating results. We use these instruments primarily to hedge our exposure associated with revenues or costs on our long-term contracts that are denominated in currencies other than our operating entities’ functional currencies. We do not hold or issue derivative financial instruments for trading or other speculative purposes.

We enter into derivative financial instruments primarily as hedges of certain firm purchase and sale commitments denominated in foreign currencies. We record these contracts at fair value on our condensed consolidated balance sheets. Depending on the hedge designation at the inception of the contract, the related gains and losses on these contracts are either deferred in stockholders’ equity as a component of accumulated other comprehensive income, until the hedged item is recognized in earnings, or offset against the change in fair value of the hedged firm commitment through earnings. Any ineffective portion of a derivative’s change in fair value and any portion excluded from the assessment of effectiveness are immediately recognized in other – net on our condensed consolidated statements of income. The gain or loss on a derivative instrument not designated as a hedging instrument is also immediately recognized in earnings. Gains and losses on derivative financial instruments that require immediate recognition are included as a component of other – net in our condensed consolidated statements of income.

We have designated all of our FX forward contracts that qualify for hedge accounting as cash flow hedges. The hedged risk is the risk of changes in functional-currency-equivalent cash flows attributable to changes in FX spot rates of forecasted transactions related to long-term contracts. We exclude from our assessment of effectiveness the portion of the fair value of the forward contracts attributable to the difference between FX spot rates and FX forward rates. At March 31, 2014, we had deferred approximately $0.3 million of net gains on these derivative financial instruments in accumulated other comprehensive income. Assuming current market conditions continue, we expect to recognize substantially all of this amount in the next twelve months.

At March 31, 2014, our derivative financial instruments consisted of FX forward contracts. The notional value of our FX forward contracts totaled $70.0 million at March 31, 2014, with maturities extending to December 2016. These instruments consist primarily of contracts to purchase or sell Canadian Dollars. We are exposed to credit-related losses in the event of nonperformance by counterparties to derivative financial instruments. We attempt to mitigate this risk by using major financial institutions with high credit ratings. The counterparties to all of our FX forward contracts are financial institutions included in our credit facility. Our hedge counterparties have the benefit of the same collateral arrangements and covenants as described under our credit facility.

17


Table of Contents

The following tables summarize our derivative financial instruments at March 31, 2014 and December 31, 2013:

March 31,
2014
December 31,
2013
(In thousands)

Derivatives Designated as Hedges:

FX Forward Contracts:

Location

Accounts receivable-other

$ 1,920 $ 1,139

Other assets

$ 224 $ 94

Accounts payable

$ 2,139 $ 581

Other liabilities

$ 1,154 $ 603

Derivatives Not Designated as Hedges:

FX Forward Contracts:

Location

Accounts receivable-other

$ 381 $ 464

Other assets

$ 26 $ 50

Accounts payable

$ 28 $ 10

Other liabilities

$ 3 $

The effects of derivatives on our financial statements are outlined below:

Three Months Ended
March 31,
2014 2013
(In thousands)

Derivatives Designated as Hedges:

Cash Flow Hedges:

FX Forward Contracts:

Amount of loss recognized in other comprehensive income

$ (1,314 ) $ (2,998 )

Gain (loss) reclassified from accumulated other comprehensive income into earnings: effective portion

Location

Revenues

$ 163 $ (531 )

Cost of operations

$ (1,026 ) $ (889 )

Other-net

$ 10 $ 15

Gain recognized in income: portion excluded from effectiveness testing

Location

Other-net

$ 435 $ 192

Derivatives Not Designated as Hedges:

FX Forward Contracts:

Gain (loss) recognized in income

Location

Other-net

$ 67 $ (676 )

18


Table of Contents

NOTE 6 – FAIR VALUE MEASUREMENTS

Investments

The following is a summary of our available-for-sale securities measured at fair value at March 31, 2014 (in thousands):

3/31/14 Level 1 Level 2 Level 3

Mutual funds

$ 4,057 $ $ 4,057 $

U.S. Government and agency securities

2,000 2,000

Asset-backed securities and collateralized mortgage obligations

367 367

Commercial paper

4,348 4,348

Total

$ 10,772 $ 2,000 $ 8,772 $

The following is a summary of our available-for-sale securities measured at fair value at December 31, 2013 (in thousands):

12/31/13 Level 1 Level 2 Level 3

Mutual funds

$ 4,001 $ $ 4,001 $

U.S. Government and agency securities

3,000 3,000

Asset-backed securities and collateralized mortgage obligations

425 425

Commercial paper

7,748 7,748

Total

$ 15,174 $ 3,000 $ 12,174 $

We estimate the fair value of investments based on quoted market prices. For investments for which there are no quoted market prices, we derive fair values from available yield curves for investments of similar quality and terms.

Derivatives

Level 2 derivative assets and liabilities currently consist of FX forward contracts. Where applicable, the value of these derivative assets and liabilities is computed by discounting the projected future cash flow amounts to present value using market-based observable inputs, including FX forward and spot rates, interest rates and counterparty performance risk adjustments. At March 31, 2014 and December 31, 2013, we had forward contracts outstanding to purchase or sell foreign currencies, primarily Canadian Dollars, with a total fair value of $(0.7) million and $0.6 million, respectively.

Other Financial Instruments

We used the following methods and assumptions in estimating our fair value disclosures for our other financial instruments, as follows:

Cash and cash equivalents and restricted cash and cash equivalents . The carrying amounts that we have reported in the accompanying condensed consolidated balance sheets for cash and cash equivalents and restricted cash and cash equivalents approximate their fair values due to their highly liquid nature.

Long-term and short-term debt . We base the fair values of debt instruments on quoted market prices. Where quoted prices are not available, we base the fair values on the present value of future cash flows discounted at estimated borrowing rates for similar debt instruments or on estimated prices based on current yields for debt issues of similar quality and terms. The fair value of our debt instruments approximated their carrying value at March 31, 2014 and December 31, 2013.

NOTE 7 – STOCK-BASED COMPENSATION

Total stock-based compensation expense for all of our plans recognized for the three months ended March 31, 2014 and 2013 totaled $1.9 million and $4.5 million, respectively, with associated tax benefit recognized for the three months ended March 31, 2014 and 2013 totaling $0.7 million and $1.7 million, respectively.

19


Table of Contents

NOTE 8 – SEGMENT REPORTING

As described in Note 1, our operations are assessed based on five reportable segments. An analysis of our operations by reportable segment is as follows:

Three Months Ended
March 31,
2014 2013
(In thousands)

REVENUES:

Power Generation

$ 312,078 $ 461,463

Nuclear Operations

286,214 261,139

Technical Services

24,455 25,229

Nuclear Energy

47,780 63,516

mPower

278 304

Adjustments and Eliminations (1)

(8,788 ) (6,228 )

$ 662,017 $ 805,423

(1) Segment revenues are net of the following intersegment transfers and other adjustments:

Power Generation Transfers

$ 2,981 $ 762

Nuclear Operations Transfers

3,087 1,277

Technical Services Transfers

52 535

Nuclear Energy Transfers

2,668 3,654

mPower Transfers

$ 8,788 $ 6,228

OPERATING INCOME:

Power Generation

$ 10,542 $ 33,330

Nuclear Operations

59,528 54,724

Technical Services

14,789 14,179

Nuclear Energy

523 2,258

mPower

(26,709 ) (26,947 )

$ 58,673 $ 77,544

Unallocated Corporate (1)

(2,375 ) (8,908 )

Special Charges for Restructuring Activities

(2,658 ) (8,423 )

Total Operating Income (2)

$ 53,640 $ 60,213

Other Income (Expense) :

Interest income

419 332

Interest expense

(899 ) (818 )

Other – net

1,322 1,406

Total Other Income

842 920

Income before Provision for Income Taxes

$ 54,482 $ 61,133

(1) Unallocated corporate includes general corporate overhead not allocated to segments.

(2) Included in operating income is the following:

(Gains) Losses on Asset Disposals – Net:

Power Generation

$ $ (78 )

Nuclear Operations

Technical Services

Nuclear Energy

9

mPower

$ $ (69 )

Equity in Income of Investees :

Power Generation

$ 2,366 $ 2,107

Nuclear Operations

Technical Services

12,901 12,833

Nuclear Energy

2 (153 )

mPower

$ 15,269 $ 14,787

20


Table of Contents

NOTE 9 – EARNINGS PER SHARE

The following table sets forth the computation of basic and diluted earnings per share:

Three Months Ended

March 31,

2014 2013
(In thousands, except share and per share amounts)

Basic:

Net income attributable to The Babcock & Wilcox Company

$ 45,044 $ 47,174

Weighted average common shares

110,439,415 114,097,313

Basic earnings per common share

$ 0.41 $ 0.41

Diluted:

Net income attributable to The Babcock & Wilcox Company

$ 45,044 $ 47,174

Weighted average common shares (basic)

110,439,415 114,097,313

Effect of dilutive securities:

Stock options, restricted stock and performance shares (1)

446,628 639,841

Adjusted weighted average common shares

110,886,043 114,737,154

Diluted earnings per common share

$ 0.41 $ 0.41

(1) At March 31, 2014 and 2013, we have excluded from our diluted share calculation 1,301,836 and 1,852,891 shares, respectively, related to stock options, as their effect would have been antidilutive.

21


Table of Contents
Item 2. Management’s Discussion and Analysis of Financial Condition and Results of Operations

CAUTIONARY STATEMENT CONCERNING FORWARD-LOOKING STATEMENTS

The following information should be read in conjunction with the unaudited condensed consolidated financial statements and the notes thereto included under Item 1 of this report and the audited consolidated financial statements and the related notes and Item 7 “Management’s Discussion and Analysis of Financial Condition and Results of Operations” included in our annual report on Form 10-K for the year ended December 31, 2013 (our “2013 10-K”).

In this quarterly report on Form 10-Q, unless the context otherwise indicates, “we,” “us” and “our” mean The Babcock & Wilcox Company (“B&W”) and its consolidated subsidiaries.

We are including the following discussion to inform our existing and potential security holders generally of some of the risks and uncertainties that can affect our company and to take advantage of the “safe harbor” protection for forward-looking statements that applicable federal securities law affords.

From time to time, our management or persons acting on our behalf make forward-looking statements to inform existing and potential security holders about our company. These statements may include projections and estimates concerning the timing and success of specific projects and our future backlog, revenues, income and capital spending. Forward-looking statements are generally accompanied by words such as “estimate,” “project,” “predict,” “believe,” “expect,” “anticipate,” “plan,” “seek,” “goal,” “could,” “intend,” “may,” “should” or other words that convey the uncertainty of future events or outcomes. In addition, sometimes we will specifically describe a statement as being a forward-looking statement and refer to this cautionary statement.

These forward-looking statements include, but are not limited to, statements that relate to, or statements that are subject to risks, contingencies or uncertainties that relate to:

our business strategy;

future levels of revenues (including our backlog and projected claims to the extent either may be viewed as an indicator of future revenues), operating margins, income from operations, net income or earnings per share;

anticipated levels of demand for our products and services;

future levels of research and development, capital, environmental or maintenance expenditures;

our beliefs regarding the timing and effects on our businesses of certain environmental and tax legislation, rules or regulations;

the success or timing of completion of ongoing or anticipated capital or maintenance projects;

expectations regarding the acquisition or divestiture of assets and businesses;

our share repurchase or other return of capital activities;

our ability to maintain appropriate insurance and indemnities;

the potential effects of judicial or other proceedings, including tax audits, on our business or businesses, financial condition, results of operations and cash flows;

the anticipated effects of actions of third parties such as competitors, or federal, foreign, state or local regulatory authorities, or plaintiffs in litigation;

the effective date and expected impact of accounting pronouncements;

our plans regarding the design, research and development, financing and deployment of the B&W mPower TM reactor; and

anticipated benefits, timing and changes associated with cost reduction and efficiency improvement activities.

In addition, various statements in this quarterly report on Form 10-Q, including those that express a belief, expectation or intention, as well as those that are not statements of historical fact, are forward-looking statements.

We have based our forward-looking statements on our current expectations, estimates and projections about our industries and our company. We caution that these statements are not guarantees of future performance and you should not rely unduly on them, as they involve risks, uncertainties and assumptions that we cannot predict. In addition, we have based many of these forward-looking statements on assumptions about future events that may prove to be inaccurate. While our management considers these assumptions to be reasonable, they are inherently subject to significant business, economic, competitive, regulatory and other risks, contingencies and uncertainties, most of which are difficult to predict and many of which are beyond our control. Accordingly, our actual results may differ materially from the future performance that we have expressed or forecast in our forward-looking statements. Differences between actual results and any future performance suggested in our forward-looking statements could result from a variety of factors, including the following:

decisions on spending and trends by power-generating companies and by the U.S. Government, including continuing appropriations by Congress and the automatic budget cuts (or sequestration) established by the Budget Control Act of 2011;

22


Table of Contents
the highly competitive nature of our businesses;

general economic and business conditions, including changes in interest rates and currency exchange rates;

general developments in the industries in which we are involved;

cancellations of and adjustments to backlog and the resulting impact from using backlog as an indicator of future earnings;

our ability to perform projects on time and on budget, in accordance with the schedules and terms established by the applicable contracts with customers;

changes in our effective tax rate and tax positions;

our ability to maintain operational support for our information systems against service outages and data corruption, as well as protection against cyber-based network security breaches and theft of data;

our ability to protect our intellectual property and renew licenses to use intellectual property of third parties;

changes in estimates used in the percentage-of-completion method of accounting;

our ability to obtain and maintain surety bonds, letters of credit and similar financing;

the operating risks normally incident to our lines of business, including the potential impact of project losses, liquidated damages and professional liability, product liability, warranty and other claims against us;

our ability to manage our capital structure, including our access to capital, credit ratings, debt and ability to raise additional financing;

our ability to comply with covenants in our credit agreements and other debt instruments and the availability, terms and deployment of capital;

volatility and uncertainty of the credit markets;

our ability to successfully manage research and development projects and costs, including our efforts to successfully develop and commercialize new technologies and products;

risks associated with our restructuring of the mPower program, including the risk that we do not receive or experience delays in receiving funding from the Department of Energy (“DOE”) and the risk of exposure to claims of contractual and other liability from our current partner, customer or others;

the risks associated with integrating businesses we acquire;

our ability to obtain and maintain builder’s risk, liability, property and other insurance in amounts and on terms we consider adequate and at rates that we consider economical;

the aggregated risks retained in our captive insurance subsidiary;

the effects of asserted and unasserted claims;

results of tax audits, including a determination by the Internal Revenue Service that the spin-off or certain other transactions should be treated as a taxable transaction, and the realization of deferred tax assets;

changes in, and liabilities relating to, existing or future environmental regulatory matters;

changes in, or our failure or inability to comply with, laws and governmental regulations;

difficulties we may encounter in obtaining regulatory or other necessary permits or approvals;

adverse outcomes from legal and regulatory proceedings;

our limited ability to influence and direct the operations of our joint ventures;

potential violations of the Foreign Corrupt Practices Act;

our ability to successfully compete with current and future competitors;

the loss of key personnel and the continued availability of qualified personnel;

our inability to realize expected benefits from our Global Competitiveness Initiative and other cost reduction initiatives;

our ability to negotiate and maintain good relationships with labor unions;

changes in pension and medical expenses associated with our retirement benefit programs;

potentially inadequate systems of internal controls over financial reporting;

the ability of our suppliers to deliver raw materials in sufficient quantities and in a timely manner;

social, political and economic situations in foreign countries where we do business; and

the possibilities of natural disasters, war, other armed conflicts or terrorist attacks.

We believe the items we have outlined above are important factors that could cause estimates in our financial statements to differ materially from actual results and those expressed in a forward-looking statement made in this report or elsewhere by us or on our behalf. We have discussed many of these factors in more detail elsewhere in this

23


Table of Contents

report and in Item 1A in our 2013 10-K. These factors are not necessarily all the factors that could affect us. Unpredictable or unanticipated factors we have not discussed in this report could also have material adverse effects on actual results of matters that are the subject of our forward-looking statements. We do not intend to update our description of important factors each time a potential important factor arises, except as required by applicable securities laws and regulations. We advise our security holders that they should (1) be aware that factors not referred to above could affect the accuracy of our forward-looking statements and (2) use caution and common sense when considering our forward-looking statements.

GENERAL

We operate in five segments: Power Generation, Nuclear Operations, Technical Services, Nuclear Energy and mPower. In general, we operate in capital-intensive industries and rely on large contracts for a substantial amount of our revenues. We are currently exploring growth strategies across our segments through acquisitions to expand and complement our existing businesses. We would expect to fund these opportunities by cash on hand, external financing (including debt), equity or some combination thereof.

Power Generation Segment

Our Power Generation segment’s overall activity depends mainly on the capital expenditures of electric power generating companies and other steam-using industries. Several factors influence these expenditures, including:

prices for electricity, along with the cost of production and distribution;

prices for coal and natural gas and other sources used to produce electricity;

demand for electricity, paper and other end products of steam-generating facilities;

availability of other sources of electricity, paper or other end products;

requirements for environmental improvements;

impact of potential regional, state, national and/or global requirements to significantly limit or reduce greenhouse gas emissions in the future;

level of capacity utilization at operating power plants, paper mills and other steam-using facilities;

requirements for maintenance and upkeep at operating power plants and paper mills to comply with environmental regulations and combat the accumulated effects of wear and tear;

ability of electric power generating companies and other steam users to raise capital; and

relative prices of fuels used in boilers, compared to prices for fuels used in gas turbines and other alternative forms of generation.

Our Power Generation segment plans to continue efforts to expand international offerings through acquisitions and partnering arrangements.

Nuclear Operations Segment

The revenues of our Nuclear Operations segment are largely a function of defense spending by the U.S. Government. As a supplier of major nuclear components for certain U.S. Government programs, this segment is a significant participant in the defense industry.

Technical Services Segment

The revenues and equity in income of investees of our Technical Services segment are largely a function of spending by the U.S. Government and the performance scores we and our consortium partners earn in managing and operating high-consequence operations at U.S. nuclear weapons sites and national laboratories. With its specialized capabilities of full life-cycle management of special nuclear materials, facilities and technologies, our Technical Services segment participates in the cleanup, operation and management of the nuclear sites and weapons complexes maintained by the DOE.

On January 8, 2013, we were notified that our joint venture, Nuclear Production Partners, LLC, was not selected to lead the National Nuclear Security Administration’s (“NNSA”) combined Management and Operating contract for the Y-12 National Security Complex and Pantex Plant. Since then, we have filed multiple protests with the Government Accountability Office in relation to the selection decision. On February 27, 2014, we received notification that our latest protest was dismissed. We will continue to manage these sites during the transition of these facilities to the NNSA’s new contractor, which is expected to be completed on June 30, 2014.

24


Table of Contents

Nuclear Energy Segment

Our Nuclear Energy segment’s overall activity depends mainly on the demand and competitiveness of nuclear energy. The activity of this segment depends on capital expenditures and maintenance spending of nuclear utilities. A significant portion of this segment’s activities is generated from the Canadian nuclear market, which could cause variability in our financial results depending on the level of maintenance and capital spending of Canadian utilities in a given year.

mPower Segment

This segment is developing the B&W mPower TM reactor and the associated mPower Plant through its majority-owned joint venture, Generation mPower LLC. Its activity is a function of research and development efforts for the B&W mPower TM reactor and the potential orders to be generated from various mPower Plant deployment initiatives. As part of this initiative, we were selected to receive funding and have signed a Cooperative Agreement with the DOE under its Small Modular Reactor Licensing Technical Support Program (“Funding Program”), which is expected to provide financial assistance initially totaling at least $150 million for small modular reactor (“SMR”) design engineering and licensing activities supporting a planned commercial operating date for the first mPower Plant by 2022.

The Funding Program is a cost-sharing award which requires us to use the DOE funds to cover first-of-a-kind engineering costs associated with SMR design certification and licensing efforts. The DOE will provide cost reimbursement for up to 50% of qualified expenditures incurred from April 1, 2013 to March 31, 2018. The DOE has authorized $99.3 million of funding to B&W for this award program as of March 31, 2014. Congress has allocated and designated an additional $85 million from the 2014 budget to the Cooperative Agreement; however, the DOE has not yet obligated those funds to us. In the three months ended March 31, 2014, we recognized $17.1 million associated with the funding award. We have recognized all amounts currently authorized by the DOE under the Funding Program. At March 31, 2014, we had $19.2 million of receivables outstanding from the DOE related to the funding award.

On April 14, 2014, we announced our plans to restructure the mPower program to focus on technology development. Beginning in the third quarter of 2014, we expect to slow the pace of development and invest no more than $15 million on an annual basis. We intend to work with the DOE to amend the Funding Program, including mutually agreeable program milestones for continued funding. If a mutually agreeable plan is not identified, future amounts may not be made available to us under the Funding Program.

Global Competitiveness Initiative / Other Restructuring Activities

We launched the Global Competitiveness Initiative (“GCI”) in the third quarter of 2012 to enhance competitiveness, better position B&W for growth, and improve profitability. We have identified a wide range of cost reduction activities including operational and functional efficiency improvements, organizational design changes, and manufacturing optimization. Once fully executed, these actions are expected to produce at least $75 million in annual savings. The majority of the annual savings are expected to result from efficiency improvements that were completed in 2013. The balance of the cost savings relates to manufacturing initiatives that are expected to be completed by mid-2015. In order to achieve these savings, we expect to incur total restructuring charges (cash and non-cash) of approximately $60 million. We incurred $1.5 million and $8.4 million of costs associated with GCI for the three months ended March 31, 2014 and 2013, respectively.

We continue to focus on structural changes in our operating model to drive significant margin improvement. We are targeting initiatives that will drive margin improvement in our Power Generation segment by 200 to 300 basis points and allow us to achieve a minimum 10% operating margin in our Nuclear Energy segment. These actions, along with our announced plans to restructure the mPower program, will result in employee termination benefits and other restructuring charges during 2014.

25


Table of Contents

Critical Accounting Policies and Estimates

For a summary of the critical accounting policies and estimates that we use in the preparation of our unaudited condensed consolidated financial statements, see Item 7 “Management’s Discussion and Analysis of Financial Condition and Results of Operations” in our 2013 10-K. There have been no material changes to these policies during the three months ended March 31, 2014, except as disclosed in Note 1 of the notes to condensed consolidated financial statements included in this report.

Accounting for Contracts

As of March 31, 2014, in accordance with the percentage-of-completion method of accounting, we have provided for our estimated costs to complete all of our ongoing contracts. However, it is possible that current estimates could change due to unforeseen events, which could result in adjustments to overall contract costs. A principal risk on fixed-priced contracts is that revenue from the customer is insufficient to cover increases in our costs. It is possible that current estimates could materially change for various reasons, including, but not limited to, fluctuations in forecasted labor productivity or steel and other raw material prices. In some instances, we guarantee completion dates related to our projects and provide performance guarantees. Increases in costs on our fixed-price contracts could have a material adverse impact on our condensed consolidated results of operations, financial condition and cash flows. Alternatively, reductions in overall contract costs at completion could materially improve our condensed consolidated results of operations, financial condition and cash flows. In the three months ended March 31, 2014 and 2013, we recognized changes in estimate related to long-term contracts accounted for on the percentage-of-completion basis which increased operating income by approximately $4.9 million and $14.2 million, respectively.

RESULTS OF OPERATIONS – THREE MONTHS ENDED MARCH 31, 2014 VS. THREE MONTHS ENDED MARCH 31, 2013

Selected financial highlights are presented in the table below:

Three months ended

March 31,

2014 2013 $ Change
(in thousands)

REVENUES:

Power Generation

$ 312,078 $ 461,463 $ (149,385 )

Nuclear Operations

286,214 261,139 25,075

Technical Services

24,455 25,229 (774 )

Nuclear Energy

47,780 63,516 (15,736 )

mPower

278 304 (26 )

Adjustments and Eliminations

(8,788 ) (6,228 ) (2,560 )

$ 662,017 $ 805,423 $ (143,406 )

OPERATING INCOME:

Power Generation

$ 10,542 $ 33,330 $ (22,788 )

Nuclear Operations

59,528 54,724 4,804

Technical Services

14,789 14,179 610

Nuclear Energy

523 2,258 (1,735 )

mPower

(26,709 ) (26,947 ) 238

$ 58,673 $ 77,544 $ (18,871 )

Unallocated Corporate

(2,375 ) (8,908 ) 6,533

Special Charges for Restructuring Activities

(2,658 ) (8,423 ) 5,765

Total Operating Income

$ 53,640 $ 60,213 $ (6,573 )

26


Table of Contents

Consolidated Results of Operations

Consolidated revenues decreased 17.8%, or $143.4 million, to $662.0 million in the three months ended March 31, 2014 compared to $805.4 million for the corresponding period in 2013 due primarily to decreased revenues from our Power Generation and Nuclear Energy segments totaling $149.4 million and $15.7 million, respectively. These decreases were partially offset by an increase in revenues in our Nuclear Operations segment totaling $25.1 million.

Consolidated operating income decreased $6.6 million to $53.6 million in the three months ended March 31, 2014 compared to $60.2 million for the corresponding period in 2013. Operating income includes special charges for restructuring activities totaling $2.7 million and $8.4 million in the three months ended March 31, 2014 and 2013, respectively. Excluding special charges for restructuring activities, operating income decreased $12.3 million for the three months ended March 31, 2014 compared to 2013. We experienced decreased operating income in our Power Generation and Nuclear Energy segments totaling $22.8 million and $1.8 million respectively. These decreases were partially offset by increased operating income in our Nuclear Operations, Technical Services and mPower segments totaling $4.8 million, $0.6 million and $0.2 million, respectively. We also experienced a decrease in unallocated corporate expenses totaling $6.5 million.

Power Generation

Three months ended

March 31,

2014 2013 $ Change
(in thousands)

Revenues

$ 312,078 $ 461,463 $ (149,385 )

Operating Income

10,542 33,330 (22,788 )

% of Revenues

3.4 % 7.2 %

Revenues decreased 32.4%, or $149.4 million, to $312.1 million in the three months ended March 31, 2014, compared to $461.5 million in 2013. The decrease was primarily attributable to an $85.7 million decline in our new build environmental equipment business revenues, principally driven by lower levels of engineering, procurement and construction activities as projects related to the previously enacted environmental rules and regulations near completion and uncertainties continue regarding the ultimate outcome of environmental regulations. We also experienced a $25.0 million decrease in our new build steam generation systems business due to a lower level of activity on our Berlin Station project. In addition, we experienced a decrease in revenues of $34.6 million in our aftermarket services business primarily due to a large boiler retrofit and construction project that was completed last year and lower environmental aftermarket revenues.

Operating income decreased $22.8 million to $10.5 million in the three months ended March 31, 2014 compared to $33.3 million in 2013, primarily due to the lower revenues discussed above and contract losses of $7.6 million for additional estimated costs to complete our Berlin Station project which includes estimated potential letter of credit draws for liquidated damages. These decreases were partially offset by a $4.4 million reduction in selling, general and administrative expenses associated with cost savings from GCI initiatives and a $1.6 million reduction in research and development expenditures.

Nuclear Operations

Three months ended

March 31,

2014 2013 $ Change
(in thousands)

Revenues

$ 286,214 $ 261,139 $ 25,075

Operating Income

59,528 54,724 4,804

% of Revenues

20.8 % 21.0 %

Revenues increased by 9.6%, or $25.1 million, to $286.2 million in the three months ended March 31, 2014 compared to $261.1 million in the corresponding period of 2013, primarily attributable to increased activity in the manufacturing of nuclear components for U.S. Government programs totaling $21.0 million and increased volume in our naval nuclear fuel and downblending activities totaling $4.1 million.

27


Table of Contents

Operating income increased $4.8 million to $59.5 million in the three months ended March 31, 2014 compared to $54.7 million in the corresponding period of 2013, primarily due to the increased revenues associated with the manufacturing of nuclear components for U.S. Government programs discussed above.

Technical Services

Three months ended

March 31,

2014 2013 $ Change
(in thousands)

Revenues

$ 24,455 $ 25,229 (774 )

Operating Income

14,789 14,179 610

Revenues totaled $24.5 million in the three months ended March 31, 2014, which were essentially unchanged from the corresponding period of 2013.

Operating income increased $0.6 million to $14.8 million in the three months ended March 31, 2014 compared to $14.2 million in the corresponding period of 2013. This increase was due to reduced overhead and general and administrative costs.

Nuclear Energy

Three months ended

March 31,

2014 2013 $ Change
(in thousands)

Revenues

47,780 63,516 (15,736 )

Operating Income

523 2,258 (1,735 )

% of Revenues

1.1 % 3.6 %

Revenues decreased 24.7%, or $15.7 million, to $47.8 million in the three months ended March 31, 2014 compared to $63.5 million in the corresponding period of 2013. This decrease was primarily attributable to a $13.4 million decrease in our nuclear services business due to the completion of certain maintenance and service projects that were ongoing in the corresponding period in 2013 and the continued low level of outage services available in the industries we serve. We also experienced a decrease in revenues from our nuclear equipment business due to the completion of two replacement steam generator projects that were ongoing in the prior year period.

Operating income decreased $1.8 million to $0.5 million in the three months ended March 31, 2014 compared to $2.3 million in the corresponding period of 2013, primarily attributable to the decrease in revenues noted above. This decrease was partially offset by $2.6 million of reduced selling, general and administrative expenses associated with cost savings from GCI initiatives.

mPower

Three months ended

March 31,

2014 2013 $ Change
(in thousands)

Revenues

$ 278 $ 304 $ (26 )

Operating Income

(26,709 ) (26,947 ) 238

Operating income increased $0.2 million to a loss of $26.7 million in the three months ended March 31, 2014 compared to a loss of $26.9 million in the corresponding period of 2013. Research and development activities related to the continued development of the B&W mPower™ reactor increased by $15.1 million, offset by the recognition of $17.1 million of the cost-sharing award from the DOE under the Cooperative Agreement as a reduction of research and development costs. There was no cost-sharing award recognized within the corresponding period of 2013. Selling, general and administrative expenses increased by $1.8 million compared to the corresponding period of 2013 due to higher business development expenses.

28


Table of Contents

Unallocated Corporate

Unallocated corporate expenses decreased $6.5 million to $2.4 million in the three months ended March 31, 2014, as compared to $8.9 million in the corresponding period of 2013. This decrease was attributable to the timing of healthcare cost allocations totaling $3.6 million, reduced information technology costs totaling $2.5 million largely related to costs associated with cyber security upgrades incurred in the prior year period and the realization of benefits associated with GCI initiatives.

Special Charges for Restructuring Activities

Operating income for the three months ended March 31, 2014 included $2.7 million of special charges for restructuring activities, comprising of $1.5 million of GCI charges related to facility consolidation and employee termination benefits, $0.4 million in employee termination benefits for the restructuring of our governmental segments and $0.8 million in consulting and administrative costs related to the restructuring of our mPower program. During the three months ended March 31, 2013, we recorded $4.3 million of GCI charges related to employee termination benefits and $4.1 million of GCI charges related to consulting and administrative costs.

Provision for Income Taxes

Three months ended

March 31,

2014 2013 $ Change
(in thousands)

Income before Provision for Income Taxes

$ 54,482 $ 61,133 $ (6,651 )

Income Tax Provision

13,328 16,257 (2,929 )

Effective Tax Rate

24.5 % 26.6 %

Our effective tax rate for the three months ended March 31, 2014 was approximately 24.5% as compared to 26.6% for the three months ended March 31, 2013. The effective tax rate for the three months ended March 31, 2014 was lower than our statutory rate primarily due to the receipt of a favorable ruling from the Internal Revenue Service that will allow us to amend prior year U.S. income tax returns to exclude distributions of several of our foreign joint ventures from domestic taxable income. Our effective tax rate for the three months ended March 31, 2013 reflected the impact of certain tax benefits related to the retroactive provisions of the American Taxpayer Relief Act of 2012 which was enacted on January 2, 2013.

Backlog

Backlog is not a measure recognized by generally accepted accounting principles. It is possible that our methodology for determining backlog may not be comparable to methods used by other companies. We generally include expected revenue in our backlog when we receive written confirmation from our customers. We are subject to the budgetary and appropriation cycle of the U.S. Government as it relates to our Nuclear Operations and Technical Services segments. Backlog may not be indicative of future operating results, and projects in our backlog may be cancelled, modified or otherwise altered by customers.

March 31,
2014
December 31,
2013
(Unaudited)
(In millions)

Power Generation

$ 1,982 $ 2,072

Nuclear Operations

2,850 2,369

Technical Services

1 5

Nuclear Energy

173 142

mPower

1 2

Total Backlog

$ 5,007 $ 4,590

We recorded new bookings in our Nuclear Operations segment totaling $763 million for the three months ended March 31, 2014, resulting in an increase in our Nuclear Operations backlog of $481 million since December 31, 2013. Major new awards from the U.S. Government are typically received during the fourth quarter of each year, following congressional approval of the budget for the government’s next fiscal year, which starts October 1. Due to events associated with the government shutdown and delayed budget approvals, awards anticipated in the fourth quarter of 2013 were delayed until the first quarter of 2014.

29


Table of Contents

We do not include orders of our unconsolidated joint ventures in backlog. These unconsolidated joint ventures are primarily included in our Power Generation and Technical Services segments.

Of the March 31, 2014 backlog, we expect to recognize revenues as follows:

2014 2015 Thereafter
(Unaudited)
(In approximate millions)

Power Generation

$ 436 $ 418 $ 1,128

Nuclear Operations

604 696 1,550

Technical Services

1

Nuclear Energy

44 44 85

mPower

1

Total Backlog

$ 1,086 $ 1,158 $ 2,763

At March 31, 2014, Power Generation backlog with the U.S. Government was $22.1 million, all of which was fully funded.

At March 31, 2014, Nuclear Operations backlog with the U.S. Government was $2.8 billion, of which $252.3 million had not yet been funded.

At March 31, 2014, Technical Services backlog with the U.S. Government was $1.3 million, all of which was fully funded.

At March 31, 2014, Nuclear Energy and mPower had no backlog with the U.S. Government.

Liquidity and Capital Resources

Credit Facility

On June 8, 2012, B&W entered into an Amended and Restated Credit Agreement (the “Credit Agreement”) with a syndicate of lenders and letter of credit issuers, and Bank of America, N.A., as administrative agent, which amended and restated our previous Credit Agreement dated May 3, 2010. The Credit Agreement provides for revolving credit borrowings and issuances of letters of credit in an aggregate outstanding amount of up to $700 million, and is scheduled to mature June 8, 2017. The proceeds of the Credit Agreement are available for working capital needs and other general corporate purposes. The Credit Agreement includes procedures for additional financial institutions to become lenders, or for any existing lender to increase its commitment thereunder, subject to an aggregate maximum of $1.0 billion for all revolving loan and letter of credit commitments.

The Credit Agreement is guaranteed by substantially all of B&W’s wholly owned domestic subsidiaries. Obligations under the Credit Agreement are secured by first-priority liens on certain assets owned by B&W and the guarantors (other than subsidiaries comprising our Nuclear Operations and Technical Services segments). If the corporate family rating of B&W and its subsidiaries from Moody’s is Baa3 or better (with a stable outlook or better), the corporate rating of B&W and its subsidiaries from Standard & Poor’s is BBB- or better (with a stable outlook or better), and other conditions are met, the liens securing obligations under the Credit Agreement will be released, subject to reinstatement upon the terms set forth in the Credit Agreement.

The Credit Agreement requires only interest payments on a periodic basis until maturity. We may prepay all loans under the Credit Agreement at any time without premium or penalty (other than customary LIBOR breakage costs), subject to certain notice requirements.

The Credit Agreement contains financial covenants relating to leverage and interest coverage and includes covenants that restrict, among other things, the level of debt incurrence, liens, investments, acquisitions, asset dispositions, dividends, prepayments of subordinated debt and mergers. At March 31, 2014, we were in compliance with all of the covenants set forth in the Credit Agreement.

30


Table of Contents

Loans outstanding under the Credit Agreement bear interest at our option at either the Eurocurrency rate plus a margin ranging from 1.25% to 2.25% per year or the base rate (the highest of the Federal Funds rate plus 0.50%, the one month Eurocurrency rate plus 1.0%, or the administrative agent’s prime rate) plus a margin ranging from 0.25% to 1.25% per year. The applicable margin for revolving loans varies depending on the credit ratings of the Credit Agreement. Under the Credit Agreement, we are charged a commitment fee on the unused portions of the Credit Agreement and that fee varies between 0.225% and 0.350% per year depending on the credit ratings of the Credit Agreement. Additionally, we are charged a letter of credit fee of between 1.25% and 2.25% per year with respect to the amount of each financial letter of credit issued under the Credit Agreement and a letter of credit fee of between 0.80% and 1.25% per year with respect to the amount of each performance letter of credit issued under the Credit Agreement, in each case depending on the credit ratings of the Credit Agreement. We also pay customary fronting fees and other fees and expenses in connection with the issuance of letters of credit under the Credit Agreement. In connection with entering into the Credit Agreement, we paid upfront fees to the lenders thereunder, and arrangement and other fees to the arrangers and agents of the Credit Agreement. At March 31, 2014, $15.0 million in borrowings and $158.0 million of letters of credit were outstanding under the Credit Agreement, leaving $527.0 million available for borrowings or to meet letter of credit requirements. The applicable interest rate at March 31, 2014 under this facility was 3.75% per year for revolving loans.

Based on the current credit ratings of the Credit Agreement, the applicable margin for Eurocurrency loans is 1.50%, the applicable margin for base rate loans is 0.50%, the letter of credit fee for financial letters of credit is 1.50%, the letter of credit fee for performance letters of credit is 0.875%, and the commitment fee for unused portions of the Credit Agreement is 0.25%. The Credit Agreement does not have a floor for the base rate or the Eurocurrency rate.

The Credit Agreement generally includes customary events of default for a secured credit facility. If any default occurs under the Credit Agreement, or if we are unable to make any of the representations and warranties in the Credit Agreement, we will be unable to borrow funds or have letters of credit issued under the Credit Agreement.

Other Arrangements

Certain subsidiaries within our Power Generation segment have credit arrangements with various commercial banks and other financial institutions for the issuance of letters of credit and bank guarantees in association with contracting activity. The aggregate value of all such letters of credit and bank guarantees as of March 31, 2014 was $109.5 million.

We have posted surety bonds to support contractual obligations to customers relating to certain projects. We utilize bonding facilities to support such obligations, but the issuance of bonds under those facilities is typically at the surety’s discretion. Although there can be no assurance that we will maintain our surety bonding capacity, we believe our current capacity is more than adequate to support our existing project requirements for the next twelve months. In addition, these bonds generally indemnify customers should we fail to perform our obligations under the applicable contracts. We, and certain of our subsidiaries, have jointly executed general agreements of indemnity in favor of surety underwriters relating to surety bonds those underwriters issue in support of some of our contracting activity. As of March 31, 2014, bonds issued and outstanding under these arrangements in support of contracts totaled approximately $394.5 million.

Long-term Benefit Obligations

Our unfunded pension and postretirement benefit obligations totaled $438.4 million at March 31, 2014. These long-term liabilities are expected to require use of Company resources to satisfy our future funding obligations. For the three months ended March 31, 2014, we made contributions to our pension and postretirement benefit plans totaling $8.6 million. We expect to make contributions to these plans totaling $67.4 million for the remainder of 2014.

Other

In the aggregate, our cash and cash equivalents, restricted cash and cash equivalents and investments decreased by $152.7 million to $257.3 million at March 31, 2014 from $410.0 million at December 31, 2013, primarily due to the items discussed below.

31


Table of Contents

Our working capital increased by approximately $20.4 million to $530.6 million at March 31, 2014 from $510.2 million at December 31, 2013, attributable primarily to an increase in net contracts in progress and advance billings on contracts, offset by a decline in cash and cash equivalents and accounts payable.

Our net cash used in operations was $113.5 million in the three months ended March 31, 2014, compared to $26.3 million for the three months ended March 31, 2013. This increase in cash used was primarily attributable to an increase in net contracts in progress and advance billings on contracts and a reduction in accounts payable.

Our net cash used in investing activities decreased by $15.9 million to $11.4 million in the three months ended March 31, 2014 from $27.3 million in the three months ended March 31, 2013. This decrease in net cash used in investing activities was primarily attributable to the release of restricted cash related to our captive insurer.

Our net cash used in financing activities decreased by $56.9 million to $8.6 million in the three months ended March 31, 2014 from $65.5 million for the three months ended March 31, 2013 due to a decline in the repurchase of common shares and an increase in borrowings on our Credit Agreement.

At March 31, 2014, we had restricted cash and cash equivalents totaling $38.5 million, $3.7 million of which was held in restricted foreign cash accounts, $2.8 million of which was held for future decommissioning of facilities (which we include in other assets on our condensed consolidated balance sheets) and $32.0 million of which was held to meet reinsurance reserve requirements of our captive insurer (in lieu of long-term investments).

At March 31, 2014, we had short-term and long-term investments with a fair value of $10.8 million. Our investment portfolio consists primarily of investments in government obligations and other highly liquid money market instruments. Our investments are classified as available for sale and are carried at fair value with unrealized gains and losses, net of tax, reported as a component of other comprehensive income.

Foreign Operations

Included in our total unrestricted cash and cash equivalents is approximately $186.8 million, or 89.8%, related to foreign operations and subsidiaries. In general, these resources are not available to fund our U.S. operations unless the funds are repatriated to the U.S., which would expose us to taxes we presently have not accrued in our results of operations. We presently have no plans to repatriate these funds to the U.S. as the liquidity generated by our U.S. operations is sufficient to meet the annual cash requirements of our U.S. operations.

See Note 1 to our unaudited condensed consolidated financial statements included in this report for information on new and recently adopted accounting standards.

Item 3. Quantitative and Qualitative Disclosures About Market Risk

Our exposures to market risks have not changed materially from those disclosed in Item 7A included in Part II of our 2013 10-K.

Item 4. Controls and Procedures

As of the end of the period covered by this quarterly report, we carried out an evaluation, under the supervision and with the participation of our management, including our Chief Executive Officer and Chief Financial Officer, of the effectiveness of the design and operation of our disclosure controls and procedures (as that term is defined in Rules 13a-15(e) and 15d-15(e) adopted by the SEC under the Securities Exchange Act of 1934, as amended (the “Exchange Act”)). Our disclosure controls and procedures were developed through a process in which our management applied its judgment in assessing the costs and benefits of such controls and procedures, which, by their nature, can provide only reasonable assurance regarding the control objectives. You should note that the design of any system of disclosure controls and procedures is based in part upon various assumptions about the likelihood of future events, and we cannot assure you that any design will succeed in achieving its stated goals under all potential future conditions, regardless of how remote. Based on the evaluation referred to above, our Chief Executive Officer and Chief Financial Officer concluded that the design and operation of our disclosure controls and procedures are effective as of March 31, 2014 to provide reasonable assurance that information required to be disclosed by us in the reports that we file or submit under the Exchange Act is recorded, processed, summarized and reported within the time periods specified in the rules and forms of the Securities and Exchange Commission, and such information is accumulated and communicated to management as appropriate to allow timely decisions

32


Table of Contents

regarding disclosure. There has been no change in our internal control over financial reporting during the quarter ended March 31, 2014 that has materially affected, or is reasonably likely to materially affect, our internal control over financial reporting.

33


Table of Contents

PART II

OTHER INFORMATION

Item 1. Legal Proceedings

For information regarding ongoing investigations and litigation, see Note 4 to our unaudited condensed consolidated financial statements in Part I of this report, which we incorporate by reference into this Item.

Item 1A. Risk Factors

In addition to the other information in this report, the other factors presented in Item 1A. Risk Factors in our annual report on Form 10-K for the year ended December 31, 2013 are some of the factors that could materially affect our business, financial condition or future results.

Item 2. Unregistered Sales of Equity Securities and Use of Proceeds

In November 2012, we announced that our Board of Directors authorized a share repurchase program. The following table provides information on our purchases of equity securities during the quarter ended March 31, 2014. Any shares purchased that were not part of a publicly announced plan or program are related to repurchases of common stock pursuant to the provisions of employee benefit plans that permit the repurchase of shares to satisfy statutory tax withholding obligations.

Period

Total number
of shares
purchased (1)
Average price
paid
per share
Total number of
shares purchased as
part of publicly
announced plans or
programs
Approximate dollar
value of shares that
may yet be
purchased under the
plans or programs
(in millions) (2)

January 1, 2014 – January 31, 2014

94,919 $ 34.16 92,000 $ 493.2

February 1, 2014 – February 28, 2014

121,200 $ 33.65 121,100 $ 489.1

March 1, 2014 – March 31, 2014

397,457 $ 33.02 255,300 $ 480.7

Total

613,576 $ 33.32 468,400

(1) Includes 2,919, 100 and 142,157 shares repurchased during January, February and March, respectively, pursuant to the provisions of employee benefit plans that permit the repurchase of shares to satisfy statutory tax withholding obligations.
(2) On November 7, 2012, we announced that our Board of Directors authorized us to repurchase an indeterminate number of shares of our common stock at an aggregate market value of up to $250 million in the open market during a two-year period ending on November 5, 2014. On May 7, 2013, we announced that our Board of Directors authorized us to repurchase an indeterminate number of shares of our common stock at an aggregate market value of up to $250 million. On February 26, 2014, we announced that our Board of Directors authorized us to repurchase an indeterminate number of shares of our common stock at an aggregate market value of up to $250 million. The May 2013 and February 2014 authorizations are in addition to the initial $250 million share repurchase amount authorized in November 2012. On December 9, 2013, we completed the repurchase of shares using our initial $250 million authorization. We may repurchase shares in the open market using the additional repurchase amounts authorized in May 2013 and February 2014 during a two-year period that expires February 25, 2016.

Item 4. Mine Safety Disclosures

We own an interest in and manage and operate Ebensburg Power Company, an independent power company that produces alternative electrical energy. Through one of our subsidiaries, Revloc Reclamation Service, Inc., Ebensburg Power Company operates multiple coal refuse sites in Western Pennsylvania (collectively, the “Revloc Sites”). At the Revloc Sites, Ebensburg Power Company utilizes coal refuse from abandoned surface mine lands to produce energy. Beyond converting the coal refuse to energy, Ebensburg Power Company is also taking steps to reclaim the former surface mine lands to make the land and streams more attractive for wildlife and human uses.

The Revloc Sites are subject to regulation by the federal Mine Safety and Health Administration under the Federal Mine Safety and Health Act of 1977. Information concerning mine safety violations or other regulatory matters required by Section 1503(a) of the Dodd-Frank Wall Street Reform and Consumer Protection Act and this Item is included in Exhibit 95 to this quarterly report on Form 10-Q.

34


Table of Contents
Item 6. Exhibits

Exhibit 2.1* – Master Separation Agreement dated as of July 2, 2010 between McDermott International, Inc. and The Babcock & Wilcox Company (incorporated by reference to Exhibit 2.1 to The Babcock & Wilcox Company’s Quarterly Report on Form 10-Q for the quarter ended June 30, 2010 (File No. 1-34658)).

Exhibit 3.1* – Restated Certificate of Incorporation of The Babcock & Wilcox Company (incorporated by reference to Exhibit 3.1 to The Babcock & Wilcox Company’s Quarterly Report on Form 10-Q for the quarter ended June 30, 2010 (File No. 1-34658)).

Exhibit 3.2* – Amended and Restated Bylaws of The Babcock & Wilcox Company effective September 9, 2013 (incorporated by reference to Exhibit 3.1 to The Babcock & Wilcox Company’s Current Report on Form 8-K dated September 11, 2013 (File No. 1-34658)).

Exhibit 10.1* – Cooperation Agreement among the Company and Starboard Value LP, and certain of its affiliates, dated March 12, 2014 (incorporated by reference to Exhibit 10.1 to The Babcock & Wilcox Company’s Current Report on Form 8-K dated March 12, 2014 (File No. 1-34658)).

Exhibit 10.2* + – Amended and Restated 2010 Long-Term Incentive Plan of The Babcock & Wilcox Company, dated as of February 25, 2014 (Incorporated by reference to Appendix A to The Babcock & Wilcox Company’s Definitive Proxy Statement dated March 28, 2014 (file No. 1-34658)).

Exhibit 10.3 + – Form of Non-Employee Director Grant Letter.

Exhibit 31.1 – Rule 13a-14(a)/15d-14(a) certification of Chief Executive Officer.

Exhibit 31.2 – Rule 13a-14(a)/15d-14(a) certification of Chief Financial Officer.

Exhibit 32.1 – Section 1350 certification of Chief Executive Officer.

Exhibit 32.2 – Section 1350 certification of Chief Financial Officer.

Exhibit 95 – Mine Safety Disclosure

101.INS – XBRL Instance Document

101.SCH – XBRL Taxonomy Extension Schema Document

101.CAL – XBRL Taxonomy Extension Calculation Linkbase Document

101.LAB – XBRL Taxonomy Extension Label Linkbase Document

101.PRE – XBRL Taxonomy Extension Presentation Linkbase Document

101.DEF – XBRL Taxonomy Extension Definition Linkbase Document

* Incorporated by reference to the filing indicated.
+ Management or compensatory contract.

35


Table of Contents

SIGNATURES

Pursuant to the requirements of the Securities Exchange Act of 1934, the registrant has duly caused this report to be signed on its behalf by the undersigned thereunto duly authorized.

THE BABCOCK & WILCOX COMPANY

/s/ Anthony S. Colatrella

By: Anthony S. Colatrella
Senior Vice President and Chief Financial Officer
(Principal Financial Officer and Duly Authorized Representative)

/s/ David S. Black

By: David S. Black
Vice President and Chief Accounting Officer
(Principal Accounting Officer and Duly Authorized
Representative)
May 12, 2014

36


Table of Contents

EXHIBIT INDEX

Exhibit

Number

Description
2.1* Master Separation Agreement dated as of July 2, 2010 between McDermott International, Inc. and The Babcock & Wilcox Company (incorporated by reference to Exhibit 2.1 to The Babcock & Wilcox Company’s Quarterly Report on Form 10-Q for the quarter ended June 30, 2010 (File No. 1-34658)).
3.1* Restated Certificate of Incorporation of The Babcock & Wilcox Company (incorporated by reference to Exhibit 3.1 to The Babcock & Wilcox Company’s Quarterly Report on Form 10-Q for the quarter ended June 30, 2010 (File No. 1-34658)).
3.2* Amended and Restated Bylaws of The Babcock & Wilcox Company effective September 9, 2013 (incorporated by reference to Exhibit 3.1 to The Babcock & Wilcox Company’s Current Report on Form 8-K dated September 11, 2013 (File No. 1-34658)).
10.1* Cooperation Agreement among the Company and Starboard Value LP, and certain of its affiliates, dated March 12, 2014 (incorporated by reference to Exhibit 10.1 to The Babcock & Wilcox Company’s Current Report on Form 8-K dated March 12, 2014 (File No. 1-34658)).
10.2* + Amended and Restated 2010 Long-Term Incentive Plan of The Babcock & Wilcox Company, dated as of February 25, 2014 (Incorporated by reference to Appendix A to The Babcock & Wilcox Company’s Definitive Proxy Statement dated March 28, 2014 (file No. 1-34658)).
10.3 + Form of Non-Employee Director Grant Letter.
31.1 Rule 13a-14(a)/15d-14(a) certification of Chief Executive Officer.
31.2 Rule 13a-14(a)/15d-14(a) certification of Chief Financial Officer.
32.1 Section 1350 certification of Chief Executive Officer.
32.2 Section 1350 certification of Chief Financial Officer.
95 Mine Safety Disclosure
101.INS XBRL Instance Document
101.SCH XBRL Taxonomy Extension Schema Document
101.CAL XBRL Taxonomy Extension Calculation Linkbase Document
101.LAB XBRL Taxonomy Extension Label Linkbase Document
101.PRE XBRL Taxonomy Extension Presentation Linkbase Document
101.DEF XBRL Taxonomy Extension Definition Linkbase Document

* Incorporated by reference to the filing indicated.
+

Management or compensatory contract.

TABLE OF CONTENTS